VISI INFRASTRUCTURE PRIVATE LIMITED
- No of Complaints: 2
- States (Active in): Chhattisgarh
| CIN | Not Available |
|---|---|
| Year Established | Not Available |
| Address | Not Available |
| Company Status | Not Available |
Introduction
In the world of real estate, selecting the right builder is critical for achieving your dream home without unnecessary complications. Today, we take a closer look at Visi Infrastructure Private Limited, a builder primarily operating in Chhattisgarh. This blog will delve into the builder's legal history, analyzing the complaints filed against them, the outcomes of various cases, and providing insights for potential buyers.
Overview of Visi Infrastructure Private Limited
Visi Infrastructure Private Limited has garnered some attention for its legal standing, with a recorded two complaints and a concerning track record of losing both cases filed against them. While the builder is engaged in development projects in Chhattisgarh, potential buyers should be informed of the legal implications linked to dealing with this company.
Legal Case Details
Complaints and Legal Outcomes
- Number of Complaints: 2
- Cases Won: 0
- Cases Lost: 2
Both cases reflect similar themes, where the applicants claimed that Visi Infrastructure failed to complete construction and hand over possession despite receiving full payment. The builder's defense indicated that the applicants did not adhere to the payment schedule, causing construction to halt.
Summary of Case Outcomes
In both cases lost by Visi Infrastructure, the final verdict mandated that the builder complete the construction and hand over possession within 45 days, in addition to paying interest for any delays. The recurring nature of these complaints suggests a systematic issue in fulfilling contractual obligations.
Patterns and Analysis
Cases Won
There are no instances of successful defenses or cases won by Visi Infrastructure, indicating potential systemic flaws in their business practices or project management.
Cases Lost
The two cases highlight a clear pattern:
- Similar Claims: Both cases arose from the same core issues: non-completion of construction and delay in handing over possession.
- Builder's Defense: The consistent reply from the builder was that payment disruptions by the applicants led to stalled construction, indicating a possible mismanagement or disparity in payment schedules.
Conclusion
Given the provided data, Visi Infrastructure Private Limited appears to face significant challenges concerning customer satisfaction and legal compliance. With zero cases won and a tendency to lose court decisions, potential buyers may want to proceed with caution.
Tips for Potential Buyers
- Thorough Research: Investigate the builder’s track record, particularly any legal complaints or court cases to gauge reliability.
- Contract Clarity: Ensure that all terms regarding payment schedules and project timelines are outlined clearly in your agreement.
- Seek Reviews: Speak to previous homeowners or consult online forums to gather insights about their experiences dealing with the builder.
- Legal Consultation: Before finalizing any dealings, consider consulting with a legal expert familiar with property law to better understand your rights.
General Tips for Selecting Any Builder
- Verify Credentials: Check licenses, accreditations, and financial stability.
- Assess Completed Projects: Visit previously completed projects to evaluate construction quality and adherence to timelines.
- Communication: Choose a builder who values transparency and maintains open lines of communication throughout the project.
- Document Everything: Keep a paper trail of all agreements and communications to safeguard your interests.
In summary, while Visi Infrastructure Private Limited offers projects in Chhattisgarh, potential buyers should remain vigilant and informed, ensuring their investments are secure and their expectations for a completed home are met.
No builder reviews yet. Be the first to share your thoughts!
Here you’ll find cases where others sued the builder, and the builder lost. We’ve included a simple summary and key takeaways from each case.
Analysis of the cases filed against Visi Infrastructure Private Limited, where the builder lost, revealed significant insights into its dealings with clients. The cases primarily revolved around two common themes: delayed possession claims and payment disputes.
The majority of the claims made by the applicants centered around the builder's failure to complete construction and hand over possession of their homes, despite having received full payment. This points to an apparent mismanagement or inability of the builder to adhere to project timelines and fulfill contractual obligations. The recurring nature of these claims highlights a pattern that suggests a systemic issue within the builder's operations, possibly related to project management or financial allocation.
The builder's defense consistently revolved around counter-claims of payment disputes, asserting that applicants failed to make payments as per the agreed schedule, which allegedly halted construction work. However, the outcomes of the cases indicate that this defense was insufficient to mitigate the builder's accountability for delays and non-completion of projects.
The penalties imposed by the Authority in these cases further illustrate the legal expectations surrounding timely project completion and the handover of property. The builder was ordered to complete pending constructions within a stipulated timeframe (45 days) and to pay interest on the delay, signaling a legal recognition of the applicants’ rights to timely possession.
The reasons the builder lost these cases likely stem from a combination of factors, including:
- Insufficient evidence to support their claims of payment discrepancies;
- Failure to comply with the agreed timelines for project completion;
- Inability to meet the contractual obligations of delivering completed homes to buyers.
These patterns indicate a need for buyers to exercise caution when engaging with Visi Infrastructure Private Limited. It is crucial for potential buyers to thoroughly vet the builder’s reputation, seek out previous case outcomes, and carefully consider the terms of payment and project timelines before entering into any agreements.
This table provides an analysis of individual cases that contributed to the summary above. Click on any row to expand and view complete details, and use the "Show More" button to load additional rows as needed.
| Case Number | State | Summary | Case Topic | Detailed Summary | Appellant Name | Respondent Name | Source |
|---|---|---|---|---|---|---|---|
| 4-?sh20-2023-0207 | Chhattisgarh | The applicants filed a complaint against the non-… | ["Delay in construc… | {"appellant_claim": "The applicants claimed that … | Shri Uday Ramteke | Visi Infrastructure… | https://rera.cgstate.gov.in/Content/ComplaintDocuments/Application_M-PRO-2023-02017/FILE_FINAL_ORDER_c67928e4-0e4d-483c-851a-4f4d8bf80e50.pdf |